最新工程設計合同范本

發(fā)布時間：2024-03-18

最新工程設計合同范本（精選17篇）

最新工程設計合同范本篇16

　　Design Contract for Construction Project (II)

　　(專業(yè)建設工程設計合同)

　　(Design Contract for Professional Construction Project)

　　工程名稱： 10KV變電所新建工程

　　Project Name：10KV Substation New Construction

　　工程地點：

　　Project Site：

　　合同編號：Contract No.：

　　(由設計人編填) (Filled in by Designer)

　　設計證書等級：設證甲級A121001826

　　Design Certification Rank: Design Certificate Class A 121001826

　　發(fā) 包人：Employer:

　　設計人：電力勘察設計院

　　Designer: Electric Power Survey Design Institute

　　簽訂日期：Date:

　　中華人民共和國建設部國家工商行政管理局

　　Supervised and Manufactured byMinistry of Construction of People’s Republic of

　　China and the State Administration of Industry and Commerce

　　發(fā)包人：Employer:

　　設計人：電力勘察設計院 Designer: Electric Power Survey Design Institute

　　發(fā)包人委托設計人承擔 10KV變電所新建工程設計，工程地點為，經雙方協(xié)商一致，簽訂本合同，共同執(zhí)行。

　　The Employer entrusts the Designer to undertake 10KV Star Mall Plaza 1 # Substation New Construction; the project site is No.6, Bei’Er Zhong Road, Tiexi District, Shenyang City. Upon agreement by both parties through consultation, the two parties shall sign and implement the Contract jointly.

　　第一條本合同簽訂依據(jù) Article 1: This Contract is signed in accordance with:

　　1.1《中華人民共和國合同法》、《中華人民共和國建筑法》和《建設工程勘察設計市場管理規(guī)定》。

　　1.1 Contract Law of the People’s Republic of China, Construction Law of the People's Republic of China and Market regulations of Construction Survey and Design.

　　1.2國家及地方有關建設工程勘察設計管理法規(guī)和規(guī)章。

　　1.2 Laws and regulations of the related state and local construction survey and design management.

　　1.3建設工程批準文件。1.3 Documents of Approval for Construction.

　　第二條　設計依據(jù)Article 2 Design Basis

　　2.1發(fā)包人給設計人的委托書或設計中標文件

　　2.1 The Trust Deed or Design Documents of the tender accepted provided to the designer by the employer;

　　2.2發(fā)包人提交的基礎資料2.2 Fundamental materials submitted by the employer;

　　2.3設計人采用的主要技術標準是：2.3 The major technical standards adopted by the designer are:

　　B-01R5-SJ-02-20xx標準、規(guī)程、規(guī)范

　　B-01R5-SJ-02-20xx Standards, Procedures, Norms

　　第三條　合同文件的優(yōu)先次序Article 3 Priority of Contract Document

　　構成本合同的文件可視為是能互相說明的，如果合同文件存在歧義或不一致，則根據(jù)如下優(yōu)先次序來判斷：

　　The documents consisting of this Contract may be deemed as demonstrating mutually; if there is any ambiguity or discordance in the contract document, the following priority shall be followed to judgment,

　　3.1合同書 3.1 The Contract;

　　3.2中標函(文件) 3.2 Letter of Acceptance (Document);

　　3.3發(fā)包人要求及委托書 3.3 Requirements of the employer and Letter of Authority;

　　3.4投標書 3.4 The Tender

　　第四條本合同項目的名稱、規(guī)模、階段、投資及設計內容(根據(jù)行業(yè)特點填寫)

　　Article 4 Name, Scale, Phase, Investment and design Content for the Contract Items (fill in based on industry characteristics)

　　10KV星摩爾購物廣場1#變電所新建工程

　　10KV Star Mall Plaza 1 # Substation New Construction

　　變電所電氣及10KV進線

　　Electric and 10KV inlet wire of the substation

　　變電所設在地下，內設6臺1600KVA變壓器及2臺1250KVA變壓器。

　　The substation is underground, with six 1,600KVA transformers and two 1,250KVA transformers inside.

　　10KV電源分別由勸工變、歷工變電所各新出電纜新路徑電纜敷設至用戶

　　變電所。

　　The 10KV power line is laid along the new cable roads of Quangong Substation and Ligong Substation respectively, toward the customer substation with cables.

　　第五條發(fā)包人向設計人提交的有關資料、文件及時間

　　Article 5 Relevant materials, documents and time submitted to the designer

　　本工程供電方案 1份 20xx-2-25

　　Power supply scheme of this project 1 25 February, 20xx

　　用電負荷資料 1份 20xx-2-25

　　by the employer

　　Electricity load data 1 25 February, 20xx

　　第六條設計人向發(fā)包人交付的設計文件、份數(shù)、地點及時間

　　Article 6 Documents, number of copies, location and time submitted to the employer by the designer

　　設計圖紙 8份 20xx-04-15

　　Design drawing 8 copies 15 April, 20xx

　　概算書 6份 20xx-04-15

　　Book of estimates 6 copies 15 April, 20xx

　　注：待發(fā)包人結清全部設計費后，由設計人將設計文件交付沈陽供電公司客戶工程部

　　Note: After the party issuing contract settles up the total design fee, the above design documents will be submitted to the Project Division of Shenyang Power Supply Company by the designer.

　　第七條　　費用Article 7 Expenditure

　　7.1雙方商定，本合同的設計費為設計費按設計價格(20xx)10號文計取萬元。收費依據(jù)和計算方法按國家和地方有關規(guī)定執(zhí)行，國家和地方沒有規(guī)定的，由雙方商定。

　　7.1 It is agreed between both parties that the design fee under this contract is calculated and charged according to the document No.10 (20xx) Design Prices. The charging basis and method are in accordance with relevant national and local provisions, and will be determined by both parties through negotiation, if there is no relevant national or local provision.

　　7.2 如果上述費用為估算設計費，則雙方在初步設計審批后，按批準的初步設計概算核算設計費。工程建設期間如遇概算調整，則設計費也應做相應調整。

　　7.2 If the above expense is estimated design fee, both parties shall check the design fee as per the approved budgetary estimate of the preliminary design, after the examination and approval of preliminary design. During the construction of this project, if there is any adjustment in budgetary estimate, the design fee will also be adjusted correspondingly.

　　第八條　　支付方式Article 8 Form of Payment

　　8.1本合同生效后三天內，發(fā)包人支付設計費總額，計 16 萬元作為定金(合同結算時，定金抵作設計費)。

　　8.1 The party issuing contract shall pay the total design fee, within three days after the execution of this contract, that is, 160000 RMB as a deposit (the deposit will be seen as a part of design fee, at the time of contract settlement).

　　8.2設計人提交　全部　設計文件之前，發(fā)包人結清設計費，不留尾款。

　　8.2 Before the designer submits all design documents. the design charge is all squared by the employer, and no final payment left.

　　8.3雙方委托銀行代付代收有關費用。

　　8.3 Both parties commission bank to pay and collect related fees.

　　第九條　　雙方責任Article 9 Responsibility of Two Parties

　　9.1 發(fā)包人責任9.1 Responsibility of the Employer

　　9.1.1 The Employer shall deliver basic materials and documents to the designer within the specified time in accordance requirements stipulated in Article 5, and shall be responsible for their completeness, correctness and time limit. The employer shall not request the designer to design by violating the concerned national standards.

　　If it exceeds the prescribed time limit within fifteen (15) days when the employer delivers above materials and documents, the designer can postpone accordingly the time of delivering the design documents in accordance with Article 6 in the Contract; if it exceeds the prescribed time limit over fifteen (15) days when the employer delivers above materials and documents, the designer is entitled to decide again the time of delivery of design documents.

　　9.1.2 When the employer alters entrusted design items, scale and conditions, or delivers the wrong materials, or delivers mostly revised materials so that the designer rework for the design, the employer shall pay for rework cost for the designer based on the amount of the work performed by the designer except the supplemental agreement (or contract ) signed separately, and the relevant articles specified again by both parties through the consultation.

　　Prior to signing the contract, if the employer has satisfied to design work which is done by the designer, the employer shall pay the corresponding design charge.

　　在未簽訂合同前發(fā)包人已同意，設計人為發(fā)包人所做的各項設計工作，發(fā)包人應支付相應設計費。

　　9.1.3 During implementation of the Contract, when the employer requests to terminate and cancel the contract, the down payment paid by the employer shall not be returned if the designer doesn’t begin the design work; if the designer starts the design, the employer shall pay half of design charge in the phase if it is less than half of the actual amount of work performed by the designer; if it exceeds the half, the full design charge in the phase shall be paid in all.

　　9.1.4 The employer shall pay the down payment in accordance with stipulations of the Contract. Reception of the down payment is the mark of commencement of design work for the designer. If the down payment is not received, the designer is entitled to put off the time of commencement of design work, and postpone accordingly the time of delivery of documents.

　　9.1.5發(fā)包人應按本合同規(guī)定的金額和日期向設計人支付設計費，每逾期支付一天，應承擔應支付金額千分之二的逾期違約金，且設計人提交設計文件的時間順延。逾期超過30天以上時，設計人有權暫停履行下階段工作，并書面通知發(fā)包人.發(fā)包人的上級或設計審批部門對設計文件不審批或本合同項目停緩建，發(fā)包人均應支付應付的設計費。

　　9.1.5 The Employer should pay charges for design to the Designer at the amount and date provided in this Contract. For each day of overdue payment, 2‰ of the overdue payment shall be paid as damages for overdue payment and the time for delivery by the Designer shall be extended accordingly. Where the delay of payment has exceeded 30 days, the Designer shall have the right to suspend the performance of the work at the next stage and give written notice to the Employer. In case the higher authority or competent department of design approval would not approve the design documents or the engineering construction of this contract is suspended or stopped, the Employer should pay the payable charges for design.

　　9.1.6發(fā)包人要求設計人比合同規(guī)定時間提前交付設計文件時，須征得設計人同意，不得嚴重背離合理設計周期，且發(fā)包人應支付趕工費。

　　9.1.6 The employer requests the designer should deliver the design documents ahead of the time specified by the Contract, it shall need the approval of the designer, and shall not deviate gravely from the rational design period, and the employer shall pay for the crashing charge.

　　9.1.7發(fā)包人應為設計人派駐現(xiàn)場的工作人員提供工作、生活及交通等方面的便利條件及必要的勞動保護裝備。

　　9.1.7 The Employer should offer conveniences in aspects of working, living and traffic and necessary labor-protection equipments.

　　9.1.8設計文件中選用的國家標準圖、部標準圖及地方標準圖由發(fā)包人負責解決。

　　9.1.8 The Employer shall be responsible for the national standard drawing, ministerial standard drawing and local standard drawings.

　　9.1.9承擔本項目外國專家來設計人辦公室工作的接待費(包括傳真、電話、復印、辦公等費用)。

　　9.1.9 The Employer shall bear the expenses for receiving foreign expert in charge of the engineering to the Designer's office (including expenses on fax, telephone, copy and office affairs).

　　9.2設計人責任9.2 Responsibilities of the Designer

　　9.2.1設計人應按國家規(guī)定和合同約定的技術規(guī)范、標準進行設計，按本合同第六條規(guī)定的內容、時間及份數(shù)向發(fā)包人交付設計文件　(出現(xiàn)9.11、9.12、9.14、9.15、規(guī)定有關交付設計文件順延的情況除外).并對提交的設計文件的質量負責。

　　9.2.1 The designer shall perform the design in accordance with provisions of the State and the technical codes and standards stipulated in the Contract, deliver the design documents in accordance with contents, time and number of copies to the employer specified in Article 6 (exclusion of the case where the design documents shall be prolonged accordingly stipulated in Article 9.11, 9.12, 9.14 and 9.15), and be responsible for quality of the delivered design documents.

　　9.2.2設計合理使用年限為　　25　　年。

　　9.2.2 The design life of the engineering construction shall be 25 years.

　　9.2.3負責對外商的設計資料進行審查，負責該合同項目的設計聯(lián)絡工作。

　　9.2.3 Responsible for examining for design materials of foreign businessman, and responsible for design liaison of the Contract project.

　　9.2.4設計人對設計文件出現(xiàn)的遺漏或錯誤負責修改或補充。由于設計人設計錯誤造成工程質量事故損失，設計人除負責采取補救措施外，應免收受損失部分的設計費，并根據(jù)損失程度向發(fā)包人支付賠償金，賠償金數(shù)額由雙方商定為實際損失的 \%。

　　9.2.4 The designer shall be responsible for revision or supplement to the mistakes or omission of the design documents. The designer shall be free of the design charge of loss part besides remedial measures taken for casualty loss of construction quality caused by the designer due to the wrong design, and shall pay compensation money for the employer based on degree of loss. Amount of compensation which is decided by two parties through consultation is \% of actual loss.

　　9.2.5由于設計人原因，延誤了設計文件交付時間，每延誤一天，應減收該項目應收設計費的千分之二。

　　9.2.5 If the delivery of design documents is delayed for the Designer's reason, each day overdue will result in the reduction of 2‰ of the design charges for the project.

　　9.2.6合同生效后，設計人要求終止或解除合同，設計人應雙倍返還發(fā)包人已支付的定金。

　　9.2.6 After the contract enters into force, the Designer may require termination or cancellation of the contract and the Designer should return the down payment in double.

　　9.2.7 Upon delivery of the design documents, the Designer shall participate in the inspection on the design by the relevant higher authority as provide and shall be responsible for necessary adjustment and supplements to the content within the original scope of the design according to the inspection conclusion. The Designer shall start the construction within one year upon delivery of the design documents within the specified time limit and shall be responsible for the technological disclosure to the Employer and construction unit, handling with relevant matters on design and participation in the acceptance upon completion of the engineering construction. In case the engineering construction has not started within one year, the Designer shall still be responsible for the above work and may collect reasonable service charge for consultancy from the Employer according to the needed workload. The amount of the service charge shall be discussed and determined by the Parties.

　　第十條　　保密Article 10 Confidentiality

　　Both Parties shall protect each other’s intellectual property rights. Without prior consent, neither party shall revise, copy or transfer to a third party or use for the project other than the project of this Contract any materials and documents of the other party. Under such circumstances, the disclosing party shall be responsible for all the any consequence it resulted and shall bear the relevant compensation.

　　第十一條　　仲裁Article 11: Arbitration

　　本建設工程設計合同發(fā)生爭議，發(fā)包人與設計人應及時協(xié)商解決。也可由當?shù)亟ㄔO行政主管部門調解，調解不成時，雙方當事人同意由　沈陽　仲裁委員會仲裁。雙方當事人未在合同中約定仲裁機構，當事人又未達成仲裁書面協(xié)議的，可向人民法院起訴。

　　If any dispute arises in connection with this Engineering Service Contract, it shall be settled by friendly consultation of the Parties, or be submitted to the competent local construction administration department for mediation. Where the dispute can not be settled by mediation, it shall be submitted to the Shenyang Arbitration Committee for settlement. Where the Parties have not agreed on the arbitration organization in the Contract nor conclude arbitration agreement in written form, the dispute will be brought to the People’s Court.

　　第十二條　　合同生效及其他Article 12: Contract effective and miscellaneous

　　12.1發(fā)包人要求設計人派專人長期駐施工現(xiàn)場進行配合與解決有關問題時，雙方應另行簽訂技術咨詢服務合同。

　　12.1 As per the request of the Employer for dispatch of personnel to stay on the Construction site so as to coordinate and solve relevant issues, the individual technical consultant service contract shall be signed by both parties.

　　12.2設計人為本合同項目的服務至施工安裝結束為止。

　　12.2 Service provided by the Designer for the Project in this Contract will be concluded until the completion of construction and installation.

　　12.3 In the projects of the Contract, Designer shall not appoint manufacturers or Designers of construction materials and equipments. Where there is a necessity that Designer shall cooperate with Employer in ordering the process of construction materials and equipments, the relevant charge shall be paid by Employer.

　　12.4 The Employer entrusted the Designer to cooperate with the engineering work of imported project and design personnel undertaking relevant design assignment shall be included in all stages from enquiry, business negotiation, domestic and overseas technical inspection until the production period. The charge for overseas business trip and other relevant charge will be paid by Employer except the charge for purchasing dress.

　　12.5發(fā)包人委托設計人承擔本合同內容以外的工作服務，另行簽訂協(xié)議并支付費用。

　　12.5 Additional agreement for any other service, which Employer entrusts Designer to provide, however, out of the scope of the Contract, shall be signed and the payment shall be paid correspondingly.

　　12.6由于不可抗力因素致使合同無法履行時，雙方應及時協(xié)商解決。

　　12.6 For any failure to perform any term or condition of this Contract due to the force majeure, both parties shall, in good faith, attempt to settle amicably and by mutual agreement.

　　12.7本合同雙方簽字蓋章即生效。一式　貳　份，發(fā)包人　壹　份，設計人　壹　份。

　　12.7 The Contract is effective once after both parties stamped and signed. There are totally __two_ copies of the Contract, Employer retains __one_ copies, and Designer retains __one__ copies.

　　12.8 Once this Contract became effective, it should be registered in the Auditing Section stipulated by Provincial Administrative Ministry of Construction where the Project locates. Where is necessity mutually agreed by both parties, the Contract shall be certified by Local Administration for Industry and Commerce. This Contract is to be concluded once after both parties fulfilled their own responsibilities.

　　12.9雙方認可的來往傳真、電報、會議紀要等，均為合同的組成部分，與本合同具有同等法律效力。

　　12.9 Any correspondence, include faxes, telegram, meeting minutes agreed by both parties, are components of the Contract, which shall have the same validity with this Contract.

　　12.10未盡事宜，經雙方協(xié)商一致，簽訂補充協(xié)議，補充協(xié)議與本合同具有同等效力。

　　12.10 As for matters not covered in this Agreement, supplementary agreement may be concluded by the Parties separately and such supplementary agreement shall have the same legal validity with this Contract.

　　發(fā)包人名稱：Name of the Employer:　　　　　　　　設計人名稱：Name of the Designer:

　　(蓋章)(Stamp) (蓋章)(Stamp)

　　法定代表人：(簽字)Legal representative: (signature) 法定代表人：(簽字)Legal representative: (signature)

　　委托代理人：(簽字)Authorized proxy: (signature) 委托代理人：(簽字)Authorized proxy: (signature)

　　項目經理：(簽字)Project Manager: (signature) 項目經理：(簽字) Project Manager: (signature)

　　住所： Address: 住所：Address:

　　郵政編碼： Postcode: 郵政編碼： Postcode:

　　電　　話： Tel.: 電　　話：Tel.:

　　傳　　真： Fax: 傳　　真：Fax:

　　開戶銀行： Bank: 開戶銀行：　 Bank:

　　銀行帳號： Bank account:　　　　　　　　　銀行帳號：Bank account:

　　建設行政主管部門備案：　　　　鑒證意見：　Verification opinion:

　　Record at the competent construction

　　administration department:

　　(蓋章)　(Stamp) 　　　　　　 (蓋章)(Stamp)

　　備　案　號：　　　　　　　　　經　辦　人：

　　Record No.: Agent:

　　備案日期：年　月　日鑒證日期：　年　月　日

最近中文字幕完整版高清,宅男宅女精品国产av天堂,亚洲欧美日韩综合一区二区,最新色国产精品精品视频,中文字幕日韩欧美就去鲁

最新工程設計合同范本